Foreign Filer Report • May 27, 2020
Foreign Filer Report
Open in ViewerOpens in native device viewer
Washington, D.C. 20549
May 27, 2020
Commission File Number 001-36761
1 Temasek Avenue #36-01 Millenia Tower Singapore 039192 (Address of principal executive offices)
Indicate by check mark whether the registrant files or will file annual reports under cover of Form 20-F or Form 40- F.
Form 20-F ☒ Form 40-F ☐
Indicate by check mark whether the registrant by furnishing the information contained in this Form is also thereby furnishing the information to the Commission pursuant to Rule 12g3-2(b) under the Securities Exchange Act of 1934.
Yes ☐ No ☒
If ''Yes'' is marked, indicate below the file number assigned to the registrant in connection with Rule 12g3-2(b):
EXHIBIT 99.2 TO THIS REPORT ON FORM 6-K IS INCORPORATED BY REFERENCE IN THE REGISTRATION STATEMENT ON FORM S-8 (FILE NO. 333-201716) OF KENON HOLDINGS LTD. AND IN THE PROSPECTUSES RELATING TO SUCH REGISTRATION STATEMENT.
On May 27, 2020, Kenon Holdings Ltd.'s subsidiary OPC Energy Ltd. ("OPC") reported to the Israeli Securities Authority and the Tel Aviv Stock Exchange its periodic report (in Hebrew) for the three months ended March 31, 2020 ("OPC's Periodic Report"). English convenience translations of the (i) Report of the Board of Directors regarding the Company's Matters for the Three-Month Period ended March 31, 2020 and (ii) Condensed Consolidated Interim Financial Statements at March 31, 2020 as published in OPC's Periodic Report are furnished as Exhibits 99.1 and 99.2, respectively, to this Report on Form 6-K. In the event of a discrepancy between the Hebrew and English versions, the Hebrew version shall prevail.
,
This Report on Form 6-K, including the exhibits hereto, includes forward-looking statements within the meaning of the Private Securities Litigation Reform Act of 1995. These statements include statements with respect to OPC's business strategy and OPC's plans with respect to the Tzomet and OPC-Hadera projects, including expected COD dates and expected construction completion date for Tzomet, the expected impact of the Covid-19, the expected impact of delays, including expected compensation and insurance reimbursement for delays and expected impact on total costs for the OPC-Hadera project, the working capital deficit, its plans and expectations regarding regulatory clearances and approvals for its projects, and the technologies intended to be used thereto, statements with respect to the potential construction, operation and maintenance of the new 99MW power plant, including with respect to electricity sales, statements with respect to the expected effects of the Covid-19, the Electricity Authority ("EA") tariffs and their expected effects on OPC, including announced changes effective for 2020, expected timing and impact of planned maintenance to be performed at OPC-Rotem in 2020, the expected interpretation and impact of regulations on OPC and its subsidiaries, and OPC's adoption of certain accounting standards and the expected effects of those standards on OPC's results. These statements are based on OPC Energy Ltd. management's current expectations or beliefs, and are subject to uncertainty and changes in circumstances. These forward-looking statements are subject to a number of risks and uncertainties, many of which are beyond Kenon's and OPC 's control, which could cause the actual results to differ materially from those indicated in such forward-looking statements. Such risks include the risk that OPC may fail to obtain any required approvals for its projects or meet the required conditions and milestones for continuation of its projects, OPC may be unable to complete the development of the OPC-Hadera and Tzomet projects on a timely basis, within the expected budget, or at all, including as a result of, among others, IDE does not sign an agreement with the State of Israel and that OPC does not construct, operate or maintain the power plant or effect electricity sales as described or at all, the Covid-19 outbreak, OPC may become subject to new regulations or existing regulations may have different interpretations or impacts than expected, the accounting standards may have a material effect on OPC's results, there may be changes to the EA tariffs with different effects on OPC's results, and other risks and factors, including the impact of the Covid-19 outbreak, including those risks set forth under the heading "Risk Factors" in Kenon's Annual Report on Form 20-F filed with the SEC and other filings. Except as required by law, Kenon undertakes no obligation to update these forward-looking statements, whether as a result of new information, future events, or otherwise.
*English convenience translation from Hebrew original document.
Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.
KENON HOLDINGS LTD.
Date: May 27, 2020 By: /s/ Robert L. Rosen Name:Robert L. Rosen Title: Chief Executive Officer
The Board of Directors of OPC Energy Ltd. (hereinafter – "the Company") is pleased to present herein the Report of the Board of Directors regarding the activities of the Company and its investee companies, the financial statements of which are consolidated with the Company's financial statements (hereinafter – "the Group"), as at March 31, 2020 and for the three-month period then ended, in accordance with the Securities Regulations (Periodic and Immediate Reports), 1970 (hereinafter – "the Reporting Regulations").
The review provided below is limited in scope and relates to events and changes in the state of the Company's affairs during the period of the Report that have a material effect on the data included in the interim financial statements and on the data in the Description of the Company's Business, and is presented based on the assumption that the reader has access to, among other things, the Directors' Report and the financial statements for the year ended December 31, 2019, which were attached to the Company's Periodic Report for 2019 which was published on February 27, 2020 (Reference No.: 2020-01-016870), (hereinafter – "the Consolidated Financial Statements" and "the Periodic Report for 2019", respectively) 1 . The information included in the Periodic Report and the Consolidated Financial Statements is included herein by reference.
As at March 31, 2020, there are no warning signs, as defined in Regulation 10(B)(14) of the Reporting Regulations, that require the Company to publish a report of projected cash flows.
It is noted that in accordance with the condensed interim separate-company information (Regulation 38D), as at March 31, 2020, the Company has a deficit in the working capital, in the amount of about NIS 1.5 million. The Company's Board of Directors made an analysis of the circumstances and determined that the existence of the deficit in the Company's working capital, as stated, does not indicate a liquidity problem in the Company, taking into account, among other things, the amount thereof and the fact that the said deficit stems from short-term loans, in the amount of NIS 219 million, that were repaid subsequent to the date of the Report. According to the examination of the Board of Directors, the Coronavirus crisis (as described in Section 2 below), did not impact the said deficit in the working capital. It is noted that subsequent to the date of the Report, the Company issued debentures (Series B) as stated below. The above-mentioned information contains "forward-looking" information as defined in the Securities Law, 1968 ("the Securities Law") which is based on the Company's estimates regarding liquidity. The actual data could be significantly different than the said estimate if there is a change in one of the risk factors that were taken into account when making these estimates.
Presented together with this Report are the consolidated interim financial statements as at March 31, 2020 (hereinafter – "the Interim Statements") and on the assumption that this Report is read together with all the said report parts, which are presented herein by reference. In certain cases, details are provided regarding events that took place after the date of the financial statements and shortly before the publication date of the Report. The materiality of the information included in this Report was examined from the point of view of the Company. Occasionally, an additional detailed description has been provided in order to give a comprehensive picture of the issue at hand. The interim financial statements have been prepared in accordance with International Financial Reporting Standards (IFRSs) and in accordance with the provisions of Part D of the Securities Regulations (Periodic and Immediate Reports), 1970.
It is emphasized that the description in this Report contains "forward-looking" information, as defined in the Securities Law. Forward-looking information is uncertain information relating to the future, including projections, assessments, estimates or other information relating to a future matter or event, the realization of which is uncertain and/or outside the Company's control. The forward-looking information included in this Report is based on information or assessments existing in the Company as at the publication date of this Report.
This Directors' Report has not been audited or reviewed by the Company's auditing CPAs.
1 It is noted that in some of the cases an additional description was provided in order to present a more comprehensive picture of the matter being addressed. References to Immediate Reports in this Report include the information included in the said Immediate Reports by means of reference.
The Company is a public company the securities of which are listed for trade on the Tel Aviv Stock Exchange Ltd. (hereinafter – "the Stock Exchange").
As at the date of the Report, the Company is engaged, by itself and through a number of subsidiaries, in one reportable business segment – the generation and supply of electricity. As part of this area of activities, the Company is engaged in generation of electricity and supply thereof to private customers and to Israel Electric Company (hereinafter – "the Electric Company" or "IEC"), including in initiation, development, construction and operation of power plants and facilities for generation of energy.
It is noted that in March 20204 , the Hadera construction contractor gave notice that, taking into the quarantine instructions and restrictions on entry into Israel due to spread of the Coronavirus (COVID 19), to the extent arrival of a foreign technical team is necessary in order to perform of certain actions required to complete the acceptance tests of the Hadera Power Plant, commercial operation of the Hadera Power Plant could be delayed beyond June 2020. As at the publication date of this Report, there are delays in arrival of equipment as well as arrival of a foreign technical team required for completion of the stage of the acceptance tests of the Hadera Power Plant. The Company expects that the commercial operation date of the power plant will be in June 2020, however in light of the restrictions described, the said commercial operation date could be delayed even beyond June 2020.
In March 2020 the Electricity Authority approved Hadera's request to extend the commercial operation date by 12 months (up to March 2021). Extension of the commercial operation date was approved together with realization of the bank guarantee provided by Hadera, in the amount of NIS 1.2 million. After realization of the guarantee, Hadera provided a substitute bank guarantee as required by its conditional generation license, in the same amount. In addition, regarding Hadera's request to the lenders in Hadera's financing agreement to extend the final date for commercial operation stipulated in Hadera's financing agreement up to the end of June 2020, in March 2020, Hadera's lenders approved Hadera's said request.
2 For details regarding the arrangements provided as part of Hadera's agreements with its customers in connection with delays in the commercial operation date stated in the agreements with them, including provision of a discount by the Company in the delay period – see Section 8.5.1.2 of Part A of the Periodic Report for 2019 and Notes 25A and 25D to the consolidated financial statements.
3 The total investments is presented net of compensation from the construction contractor to which the Company is entitled in accordance with Hadera's construction agreement – see Note 25D to the consolidated financial statements.
4 As published in the Company's Immediate Report dated March 11, 2020 (Reference No.: 2020-01-019948). That stated therein is presented herein by means of reference.
As at the date of this Report, the Company estimates that part of the costs stemming from the said delay, including lost profits, will be covered by Hadera's insurance policy pursuant to the terms of the said policy. In addition, in accordance with the construction agreement, Hadera is entitled to agreed-to compensation (limited to the ceiling stipulated in the construction agreement) from the construction contractor in respect of a delay in the delivery date. Given that stated, the Company estimates that the said delay is not expected to cause a significant deviation from the Company's estimates regarding the total construction cost of the Hadera Power Plant, in the amount of about NIS 1 billion (including the acquisition cost of about NIS 60 million). As at the date of the Report, returns (reimbursements), as stated, from the Company's insurance policies and/or from the construction contractor had not yet been received. There is no certainty that the Company will be able to receive returns (reimbursements) and/or compensation in respect the full amount of its direct and indirect damages5 . For additional details – see Notes 25A and 25D to the consolidated financial statements.
5 It is emphasized that that stated above, including regarding the Company's estimates with respect to the updated expected commercial operation date of the Hadera Power Plant, coverage of the costs stemming from the delay, as stated above (including lost profits) and receipt of compensation for the delay damages, the total estimated construction cost of the Hadera Power Plant and/or with reference to the estimate that a deviation from this estimate is not expected, includes "forward-looking" information, as defined in the Securities Law, which is based on the Company's estimates as at the date of the Report, and regarding which there is no certainty it will be realized. That stated may not be realized or may be realized in a manner different than expected. As a practical matter, the commercial operation date of the Hadera Power Plant may be delayed even beyond June 2020 and the actual construction cost could be higher than this estimate – this being due to, among other things, additional delays in completion of the test-runs and operation of the Power Plant and/or as a result of other technical breakdowns and failures, an increase in costs, non-receipt of a permanent generation license and a supply license, non-receipt of required regulatory permits or approvals, and/or due to occurrence of any of the risk factors involved with completion of the power plant project or the Company's activities. In addition, if compensation is not received for all of the costs and/or damages (direct and/or indirect) in connection with the delay in completion of the construction and the commercial operation, this could have an adverse impact on the Company's results and activities. For additional details regarding the risk factors involved with construction projects, including the Hadera project – see Section 19.3 of Part A (Description of the Company's Business).
Brief description of the Group, its business environment and its areas of activity (Cont.)
Due to the continued movement (traffic) restrictions in Israel and worldwide and the need for arrival of equipment from overseas, due to the Coronavirus crisis, the Company estimates that the construction period of the Zomet Power Plant could continue beyond the end of 2022, and as at the date of the Report, it is expected to be completed in the first quarter of 2023. Completion of the construction in accordance with the construction agreement covering the Zomet Power Plant was extended by about three months parallel to issuance of the work commencement order6 .
Further to that stated in Section 8.11.7 of Part A of the Periodic Report for 2019, in May 2020 approval of Israel Lands Authority was received for the Joint Company (Zomet Netiv Limited Partnership, which was set up by Zomet and Kibbutz Netiv HLH) will have ownership rights in the land located at the Plugot intersection, which is for purposes of construction of the Zomet Power Plant, and accordingly transfer of the rights to the Joint Company, as stated, was completed. For details regarding an administrative petition filed by Zomet against the Regional Council of Shafir in respect of the amount in dispute, as stated in Section 8.11.7 of Part A of the Periodic Report for 2019 – see Note 5N to the interim consolidated financial statements.
6 It is emphasized that that stated above regarding the construction date of the Zomet Power Plant constitutes "forward-looking" information as defined in the Securities Law, regarding which there is no certainty it will be realized. As a practical matter, the completion date of the construction and the construction work could be delayed (and even significantly) or may encounter difficulties, and in this regarding there could be delays, disruptions or other breakdowns in construction of the Power Plant due to, among other things, continuation of the Coronavirus crisis, failures with respect to the construction work or equipment or as a result of occurrence of one or more of the risk factors to which the Company is exposed.
7 As a result of postponement of the maintenance date, Rotem slowed down reduction (amortization) of the maintenance component of the Rotem Power Plant commencing from March 2020. For details – see Note 1, to the interim financial statements.
8 It is emphasized that that stated above regarding the planned date for performance of the maintenance work at the Rotem Power Plant and the impact thereof on the generation activities of the Rotem Power Plant and the results thereof constitutes "forward-looking" information as defined in the Securities Law, regarding which there is no certainty it will be realized. As a practical matter, the date of performance of the maintenance work could be delayed and the said delay could impact the generation activities of the Rotem Power Plant and the results thereof in a manner different than that forecasted due to, among other things, continuation of the Coronavirus crisis or as a result of occurrence of one or more of the risk factors to which the Company is exposed.
9 The said undertaking was approved by the Company's Audit Committee and Board of Directors as a transaction that is not unusual taking into account the fact that Mr. Eyal Ofer, a relative of Mr. Idan Ofer, a beneficiary in trust that has holdings in Kenon (indirectly), the Company's controlling shareholder (see Regulation 21A of the Periodic Report for 2019), is considered a controlling shareholder of Bank Mizrahi Tefahot Ltd.
10 As at the publication date of the Report, the BOT agreement between IDE and the State of Israel had not yet been signed.
11 At the end of the said period, ownership of the Power Plant will be transferred to the State.
12 Decision No. 10 from Meeting 55, held on March 6, 2019 regarding "Regulation for Generators of Ultra-High Voltage that are Established Without a Competitive Process" and Decision No. 5 (1358) from Meeting 558 of the Electricity Authority held on May 13, 2019 regarding "Publication of Rules, Transactions and Criteria for New Consumers on the Transmission Grid'. For details regarding Decision 558 and the trade rules – see Sections 8.2.1.2 and 8.2.1.4 of Part A of the Company's Periodic Report for 2019.
13 It is noted that that stated above regarding construction of the Power Plant, includes "forward-looking" information within the meaning thereof in the Securities Law, 1968, regarding which there is no certainty it will be realized. As at the date of the Report, completion of construction of the Power Plant is dependent on, among other things, completion of planning and/or licensing processes. In addition, as a practical matter there could be delay and/or breakdowns due to, among other things, various factors, as stated above, including factors not under the Company's control or as a result of occurrence of one or more of the risk factors to which the Company is exposed, including construction risk. For additional details regarding risk factors involved with construction projects – see Section 19.3 of Part A (Description of the Company's Business).
| Category | 3/31/2020 | 12/31/2019 | Analysis |
|---|---|---|---|
| Current Assets | |||
| Cash and cash equivalents |
279,404 | 384,748 | Most of the decrease stems from investments in the Zomet project, in the amount of about NIS 263 million, deposits in restricted cash, in the amount of about NIS 65 million and debt payments, in the amount of about NIS 55 million. |
| This decrease was partly offset by taking out of short-term loans, in the aggregate amount of about NIS 219 million, and an increase in the cash balances as a result of the Company's current operating activities, in the amount of about NIS 82 million. |
|||
| For further information – see the Company's condensed consolidated statements of cash flows for the three-month period ended March 31, 2020 in the financial statements. |
|||
| Short-term deposits and restricted cash |
79,307 | 115,765 | Most of the decrease derives from release of a restricted deposit, in the amount of about NIS 37 million, which was deposited as collateral for a bank guarantee securing inflow of shareholders' equity into Zomet. For additional details – see Note 5G to the interim financial statements. |
| Trade receivables and accrued income |
101,602 | 134,794 | Most of the decrease stems from a decrease in accrued income, in the amount of about NIS 32 million, mainly as a result of the impact of the seasonal factor on the sales and reduction of the generation component (as described in Note 5A to the interim financial statements). |
| Receivables and debit balances |
116,420 | 69,975 | Most of the increase stems from an increase in the balance of Value Added Tax (VAT) receivable, in the amount of about NIS 29 million, and an increase in the balance receivable from the Hadera construction contractor, in the amount of about NIS 18 million. |
| Short-term derivative financial instruments |
616 | 188 | |
| Total current assets | 577,349 | 705,470 |
| Category | 3/31/2020 | 12/31/2019 | Analysis |
|---|---|---|---|
| Non-Current Assets | |||
| Long-term deposits and restricted cash |
325,013 | 266,803 | Most of the increase stems from provision of additional collaterals in respect of interest SWAP contracts (as described in Notes 22D and 25D to the consolidated financial statements), in the amount of about NIS 34 million, and from deposit of a collateral, in the amount of about NIS 30 million, to secure a bank guarantee, as described in Note 5G to the interim financial statements. |
| This increase was partly offset by release of collateral, in the amount of about NIS 5 million, which was provided in respect of a bank guarantee in connection with Zomet's conditional license (for additional details – see Note 5G to the interim financial statements). |
|||
| Long-term prepaid expenses |
308,504 | 104,317 | Most of the increase stems from payment of an advance deposit in respect of land of Zomet (as described in Note 5N to the interim financial statements), in the amount of about NIS 187 million, and an increase in deferred expenses as part of Zomet's financing agreement, in the amount of about NIS 15 million. |
| Deferred tax assets, net | 5,263 | 5,240 | |
| Long-term derivative financial instruments |
8,629 | 7,077 | Most of the increase stems from the fair value of "call" options in Zomet, in the amount of about NIS 9 million. |
| This decrease was partly offset by a decrease deriving from change in the fair value of interest SWAP contracts, as described in Notes 22D and 25D to the consolidated financial statements. |
|||
| Property, plant and equipment |
2,420,618 | 2,344,920 | Most of the increase stems from investments in the Zomet project, in the amount of about NIS 93 million (including payment in respect of acquisition of shares, as described in Note 5J to the interim financial statements). This increase was partly offset by depreciation expenses in respect of property, plant and equipment in Rotem and Hadera (the Energy Center), in the aggregate amount of about NIS 22 million. |
| Right-of use assets | 56,009 | 56,832 | |
| Intangible assets | 4,078 | 4,259 | |
| Total non-current assets |
3,128,114 | 2,789,448 | |
| Total assets | 3,705,463 | 3,494,918 |
| Category | 3/31/2020 | 12/31/2019 | Analysis |
|---|---|---|---|
| Current Liabilities | |||
| Short-term loans and current maturities |
374,776 | 157,147 | Most of the increase stems from taking out of short-term loans, in the amount of about NIS 219 million, and update of the current maturities of loans in accordance with the repayment schedules, in the amount of about NIS 32 million. |
| The increase was partly offset by repayment of the senior debt of Rotem and Hadera, in the amount of about NIS 33 million. |
|||
| Trade payables | 120,365 | 123,812 | Most of the decrease derives from a decline in the balance of suppliers in respect of purchases of fuel, in the amount of about NIS 10 million, and the balance to Israel Electric Company, in the amount of about NIS 6 million. |
| This decrease was partly offset by an increase in the balance of the construction suppliers in Zomet, in the amount of about NIS 11 million. |
|||
| Payables and other credit balances |
38,512 | 41,641 | Most of the decrease derives from a decline in liabilities to employees in respect of salaries, in the amount of about NIS 9 million, and a decline in the balance of payables in respect of a transaction for acquisition of shares of Zomet, in the amount of about NIS 5 million. |
| This decrease was partly offset by an increase in accrued expenses, in the amount of about NIS 5 million, and from a balance of interest payable, in the amount of about NIS 4 million. |
|||
| Short-term derivative financial instruments |
23,311 | 21,678 | |
| Current maturities of lease liabilities |
2,411 | 2,400 | |
| Current taxes payable | 9,725 | – | The increase stems from liabilities for taxes on income in Rotem. |
| Total current liabilities |
569,100 | 346,678 |
| Category | 3/31/2020 | 12/31/2019 | Analysis |
|---|---|---|---|
| Non-Current Liabilities | |||
| Long-term loans from banks and others |
1,726,226 | 1,740,607 | Most of the decrease stems from update of the current maturities of the loans, in the amount of about NIS 32 million, and a decline in the linkage differences in respect of the senior debt of Hadera and Rotem, in the amount of about NIS 8 million. |
| On the other hand, there was an increase in the loans deriving from a withdrawal by Zomet, in the amount of about NIS 25 million, as part of Zomet's financing agreement. |
|||
| Debentures | 252,309 | 252,309 | |
| Long-term lease liabilities |
15,680 | 15,960 | |
| Long-term derivative financial instruments |
29,433 | – | The increase stems from change in the fair value of interest SWAP contracts, as described in Notes 22D and 25N to the consolidated financial statements. |
| Other long-term liabilities |
2,340 | 2,307 | |
| Employee benefits | 177 | 177 | |
| Deferred taxes, net | 287,510 | 281,105 | Most of the increase stems from update of the deferred taxes as a result of income for the period in Rotem. |
| Total non-current liabilities |
2,313,675 | 2,292,465 | |
| Total liabilities | 2,882,775 | 2,639,143 |
The Group's activities are subject to seasonal fluctuations as a result of changes in the official Time of Use of Electricity Tariff (hereinafter – "the TAOZ"), which is regulated and published by the Electricity Authority. The year is broken down into 3 seasons: "summer" (July and August), "winter" (December, January and February) and "transition" (March through June and September through November). In general, the electricity tariffs are higher in the summer and the winter than the tariffs in the transition periods.
3. Results of operations for the three-month period ended March 31, 2020 (in thousands of NIS) (Cont.)
| For the Three Months Ended |
||||
|---|---|---|---|---|
| Category | 3/31/2020 | 3/31/2019 | Analysis | |
| Sales | 312,551 | 353,699 | For detail regarding the change in the sales – see Section 6, below. |
|
| Cost of sales (less depreciation and amortization) |
205,129 | 223,550 | For detail regarding the change in the cost of sales – see Section 7, below. |
|
| Depreciation and amortization |
22,836 | 26,830 | Most of the decrease stems from a change in the estimated useful life of various components in the Rotem Power Plant, commencing from the fourth quarter of 2019 (for details – see Note 2E to the Consolidated Financial Statements). |
|
| Gross profit | 84,586 | 103,319 | ||
| Administrative and general expenses |
15,053 | 16,953 | Most of the decrease derives from a decrease in legal expenses and professional services, mainly due to completion of the Tamar arbitration. |
|
| Other income, net | 70 | 1,001 | ||
| Operating income | 69,603 | 87,367 | ||
| Financing expenses, net | 15,713 | 18,863 | Most of the decrease stems from changes in the fair value of "call" options, in the amount of about NIS 5 million, and the impact of changes in the exchange rate of the dollar/shekel, in the amount of about NIS 3 million. |
|
| On the other hand, there was an increase in expenses relating to CPI linkage differences in respect of the senior debt of Rotem, in the amount of about NIS 5 million (mainly in light of the hedging results with reference to linkage). |
||||
| Income before taxes on income |
53,890 | 68,504 | ||
| Taxes on income | 15,927 | 17,595 | The decrease derives from lower income in the first quarter of 2020 compared with the corresponding quarter last year. |
|
| Income for the period | 37,963 | 50,909 | ||
| Attributable to: | ||||
| The Company's shareholders |
27,761 | 39,611 | ||
| Holders of non-controlling interests |
10,202 | 11,298 |
The Company defines EBITDA as earnings (losses) before depreciation and amortization, net financing expenses or income and taxes on income. EBITDA is not recognized under IFRS or under any other generally accepted accounting standards as an indicator for the measurement of financial performance and should not be considered a substitute for profit or loss, cash flows from operating activities or other terms of operational performance or liquidity prescribed under IFRS.
EBITDA is not intended to represent monies that are available for distribution of dividends or other uses, since such monies may be used for servicing debt, capital expenditures, working capital and other liabilities. EBITDA is characterized by limitations that impair its use as an indicator of the Company's profitability, since it does not take into account certain costs and expenses deriving from the Company's business, which could materially affect its net income, such as financing expenses, taxes on income and depreciation.
The Company believes that the EBITDA data provides transparent information that is useful to investors in examining the Company's operating performances and in comparing them against the operating performance of other companies in the same sector or in other sectors with different capital structures, debt levels and/or income tax rates. This data item is also used by Company management when examining the Company's performance.
Set forth below is a calculation of the EBITDA data item for the periods presented. Other companies may calculate the EBITDA differently. Therefore, the EBITDA presentation herein may differ from those of other companies.
Calculation of the EBITDA (in thousands of NIS):
| For the Three Months Ended March 31 |
|||
|---|---|---|---|
| 2020 | 2019 | ||
| Sales | 312,551 | 353,699 | |
| Cost of sales (less depreciation and amortization) | (205,129) | (223,550) | |
| Administrative and general expenses (less depreciation and | |||
| amortization) | (14,384) | (16,339) | |
| Other income | 70 | 1,001 | |
| EBITDA | 93,108 | 114,811 |
Set forth below are details of the sales, generation and purchases of electricity of the Rotem power plant and the Hadera energy center (in millions of KW hours):
| For the Three Months Ended March 31 |
|||
|---|---|---|---|
| 2020 | 2019 | ||
| Sales to private customers | 900 | 969 | |
| Sales to the System Administrator | 97 | 43 | |
| Total sales | 997 | 1,012 |
| For the Three Months Ended March 31 |
||
|---|---|---|
| 2020 | 2019 | |
| Generation of electricity |
987 | 984 |
| Purchase of electricity from the System Administrator | 10 | 28 |
| Total sales | 997 | 1,012 |
| For the Three Months Ended March 31 | |||||
|---|---|---|---|---|---|
| 2020 | 2019 | ||||
| Electricity availability |
Net generation |
Electricity availability |
Net generation |
||
| (%) | (KW hours) | (%) | (KW hours) | ||
| Rotem Hadera |
100.0% 88.4% |
966 22 |
100.0% 92.8% |
961 23 |
| For the Three Months Ended March 31 |
||
|---|---|---|
| 2020 | 2019 | |
| Thousands of Tons | ||
| Generation of steam | 210 | 200 |
Set forth below is detail of the Company's revenues (in NIS thousands):
| For the Three Months Ended March 31 |
||
|---|---|---|
| 2020 | 2019 | |
| Revenues from sale of energy generated to private customers (1) |
224,519 | 259,068 |
| Revenues from sale of energy purchased for private customers (2) |
1,133 | 6,339 |
| Revenues from private customers in respect of infrastructures |
||
| services (3) |
59,872 | 67,379 |
| Revenues from sale of energy to the System Administrator (4) |
10,896 | 5,072 |
| Revenues from sale of steam (5) |
16,131 | 15,841 |
| Total revenues | 312,551 | 353,699 |
The Company's net revenues from the sale of electricity to its private customers stem from electricity sold at the generation component tariffs, as published by the Electricity Authority, with a certain discount. The weighted-average generation component tariff for 2020, as published by the Electricity Authority, is NIS 0.2678 per KW hour. This weighted-average is attributed to the mix of consumption in the market, which differs from that of the customers of Rotem and Hadera. In 2019, the weighted-average of the generation component tariff was NIS 0.2909 per KW hour. In addition, the Company's revenues from sale of steam are linked partly to the price of gas and partly to the Consumer Price Index.
Set forth below is detail of the Company's cost of sales (less depreciation and amortization) broken down into the following components (in NIS thousands):
| For the Three Months Ended March 31 |
||
|---|---|---|
| 2020 | 2019 | |
| Gas and diesel oil (1) Expenses to IEC for infrastructure services and purchase of |
122,685 | 126,839 |
| electricity (2) |
61,005 | 73,718 |
| Gas transmission costs | 8,037 | 8,046 |
| Operating expenses (3) |
13,402 | 14,947 |
| Total cost of sales (less depreciation and amortization) | 205,129 | 223,550 |
| For the Three Months Ended March 31 |
|||
|---|---|---|---|
| 2020 | 2019 | ||
| Gas consumption (MMBTU) Average gas price (in dollars) |
7,224,872 4.71 |
7,136,595 4.77 |
For the three-month periods ended March 31, 2020 and 2019:
| For the Three Months Ended |
||||||
|---|---|---|---|---|---|---|
| Category | 3/31/2020 | 3/31/2019 | Analysis | |||
| Cash flows provided by operating activities |
82,277 | 190,636 | Most of the decrease stems from a decrease in the working capital, in the amount of about NIS 87 million (mainly as a result of VAT payments in respect of a land lease agreement, in the amount of about NIS 32 million, and lower gas payments in 2019 stemming from timing differences) and a decrease in current operating activities (mainly in light of lower income) in the amount of about NIS 25 million. |
|||
| Cash flows used in investing activities |
(309,535) | (44,699) | Most of the increase derives from higher investments in the Zomet project, in the amount of about NIS 259 million, and a deposit in restricted cash, in the amount of about NIS 42 million (mainly relating to provision of additional collaterals for index transactions and with respect to provision of a guarantee to Israel Lands Authority as a result of a land lease agreement in Zomet). |
|||
| This increase was offset by withdrawals from short-term restricted cash, in the amount of about NIS 37 million. |
||||||
| Cash flows provided by (used in) financing activities |
122,466 | (27,020) | Most of the increase stems from taking out of short-term loans, in the amount of about NIS 219 million, and a withdrawal in the framework of the financing agreement for the Zomet project, in the amount of about NIS 25 million. |
|||
| This increase was partly offset by payment in respect of acquisition of non-controlling interests in Zomet, in the amount of about NIS 26 million dividend payments to the holders of non-controlling interests, in the amount of about NIS 22 million, and payment of deferred expenses in the framework of Zomet's financing agreement, in the amount of about NIS 13 million. In addition, payment of the senior debt of Rotem was about NIS 13 million higher, the first payment was made with respect to the senior debt of Hadera, in the amount of about NIS 9 million, and the debt of Zomet was paid, in the amount of about NIS 8 million. |
The following table details the debt, cash and cash equivalents, deposits and restricted cash, as at March 31, 2020 (in thousands of NIS):
| Rotem | Hadera | Solo | Zomet | Others | Consolidated | |
|---|---|---|---|---|---|---|
| Debt (including accrued interest) |
1,166,482 | 660,075 | 506,509 | 24,672 | 1,313 | 2,359,051 |
| Cash and cash equivalents | 98,084 | 3,496 | 153,973 | 20,366 | 3,485 | 279,404 |
| Debt service reserves (out of the restricted cash)* |
136,608 | – | 66,707 | – | – | 203,315 |
– Rotem repaid the amount of about NIS 24 million (relating to principal only) of its loans.
The following table details the debt, cash and cash equivalents, deposits and restricted cash, as at December 31, 2019 (in thousands of NIS):
| Rotem | Hadera | Solo | Zomet | Others | Consolidated | |
|---|---|---|---|---|---|---|
| Debt (including accrued interest) |
1,196,650 | 670,797 | 282,864 | – | 1,282 | 2,151,593 |
| Cash and cash equivalents | 112,927 | 9,033 | 256,417 | 731 | 5,640 | 384,748 |
| Debt service reserves (out of the restricted cash)* |
138,224 | – | 66,670 | – | – | 204,894 |
The following table details the debt, cash and cash equivalents, deposits and restricted cash, as at March 31, 2019 (in thousands of NIS):
| Rotem | Hadera | Solo | Zomet | Others | Consolidated | |
|---|---|---|---|---|---|---|
| Debt (including accrued | ||||||
| interest) | 1,246,838 | 649,564 | 297,300 | – | 1,193 | 2,194,895 |
| Cash and cash equivalents and short-term deposits |
235,144 | 34,995 | 273,545 | 2,825 | 2,418 | 548,927 |
| Debt service reserves (out of the restricted cash)* |
106,810 | – | 46,489 | – | – | 153,299 |
* Including funds used for guaranteeing the debt.
As at the date of the Report, the Company and the subsidiaries were in compliance with all the financial covenants stipulated in their financing agreements and trust certificates. Set forth below is detail of financial covenants for violations14:
As at 3/31/2020
| Covenants applicable to the Company by the trust certificate for the Company's debentures (Series A) The historical debt coverage ratio, as defined in the trust certificate, may not drop below 1:1.20 The Company's shareholders' equity, as defined in the trust certificate, may not drop below NIS 80 million The Company's shareholders' equity to the total assets, as defined in the trust certificate, may not drop below 12.5% |
1:20.6 NIS 765 million 58% |
|---|---|
| Covenants applicable to the Company by the trust certificate for the Company's debentures (Series B) The ratio of the net consolidated financial debt less the financial debt designated for construction of projects that have not yet started to produce EBITDA and the adjusted EBITDA may not exceed 13 Minimum shareholders' equity of NIS 250 million A ratio of shareholders' equity to total assets at a rate of not less than 17% |
3.45 NIS 765 million 58% |
| Covenants applicable to the Company in connection with the agreement for investment of equity in Hadera The Company's shareholders' equity, up to the end of the warranty period of the construction contractor may not drop below NIS 250 million The ratio of the Company's shareholders' equity to total assets may not drop below 20% Up to the commercial operation date of Hadera, the balance of cash may not drop below NIS 90 million |
NIS 765 million 58% NIS 154 million |
| Covenants applicable to Rotem ADSCR (in the preceding 12 months) of 1.05–1.1 depending on supply of electricity to Israel Electric Company ADSCR (in the upcoming 12 months) of 1.05–1.1 depending on supply of electricity to Israel Electric Company LLCR of 1.05–1.1 depending on supply of electricity to Israel Electric Company |
2.49 1.58 1.84 |
| Covenants applicable to Hadera Minimum expected DSCR of 1.10 Average expected DSCR of 1.10 LLCR of 1.10 |
1.3 1.97 2.02 |
| Covenants applicable to Zomet Minimum expected ADSCR of 1.05 Average expected ADSCR of 1.05 LLCR of 1.05 |
1.3 1.5 1.51 |
14 The ADSCR data (in the preceding 12 months), ADSCR data (in the upcoming 12 months), minimum expected DSCR, average expected DSCR, minimum expected ADSCR, average expected ADSCR and LLCR, are based on data that constitute "forward-looking" information, as defined in the Securities Law, which are based on the Company's estimates, and which are conditioned and contingent on various factors, among others, the generation component and the actual revenues and expenses. Accordingly, the said information may not be realized or may be realized in a manner different than expected.
For details – see Section 1 above and Notes 5 and 6 to the interim consolidated financial statements.
For details regarding the Company's outstanding liabilities – see the Immediate Report regarding outstanding liabilities by maturity dates that is published by the Company concurrent with publication of this report.
Set forth below are details regarding the Company's debentures (Series B), which were issued in April 2020:
| Name of the series Issuance date Total nominal value on the date of issuance |
Series B April 26, 2020 NIS 400,000,000 par value |
|---|---|
| Nominal value on the date of the report | NIS 400,000,000 par value |
| Nominal value after revaluation based on | NIS 400,000,000 par value |
| the linkage terms Amount of the interest accrued as |
– |
| included in the financial statements as at | |
| March 31, 2020 |
|
| The fair value as included in the financial | – |
| statements as at March 31, 2020 |
|
| Stock market value on March 31, 2020 | – |
| Type of interest and interest rate | Fixed annual interest at the rate of 2.75%. |
| Principal payment dates | 16 unequal semi-annual payments, to be paid on March 31 and September 30 of each of the years from 2021 to 2028 (inclusive). |
| Interest payment dates | The interest on the outstanding balance as it will be from |
| time to time on the principal of the debentures (Series B) |
|
| is payable commencing from September 2020 twice a | |
| year (except for 2020) on September 30, 2020, and on |
|
| March 31 and September 30 of each of the years from 2021 to 2028 (inclusive). |
|
| The interest payments are to be made for the period of six | |
| months that ended on the last day prior to the relevant | |
| interest payment date, except for the first interest payment | |
| that is to be made on September 30, 2020, and is to be |
|
| paid for the period that commenced on the first trading | |
| day after the tender date of the debentures (Series B) and that ends on the last day prior to the said payment date, |
|
| and is to be calculated based on the number of days in the | |
| said period and on the basis of 365 days per year. | |
| Linkage basis and terms | The principal of the debentures (Series B) and the interest |
| thereon are linked to the increase in the Consumer Price |
|
| Index (CPI) against the CPI for March 2020 that was |
|
| published on April 15, 2020. The linkage terms will not |
|
| Are they convertible into another security | be changed during the period of the debentures. No. |
| Right of the Company to make early repayment Was a guarantee provided for payment of |
The Company has the right to make early repayment pursuant to the conditions in the trust certificate. No. |
|---|---|
| the Company's liabilities based on the debentures Name of trustee |
Reznik Paz Nevo Trustees Ltd. |
| Name of the party responsible for the series of liability certificates with the trustee |
Michal Avatlon and/or Hagar Shaul |
| Contact information | Address: 14 Yad Harutzim St., Tel-Aviv Telephone: 03–6389200 Fax: 03–6389222 E–mail: [email protected] |
| Rating of the debentures since the issuance date |
Rating of ilA– by Standard & Poor's Maalot from February 2020. Rating of A3.il by Midroog Ltd. from April 2020. See the Company's Immediate Reports dated February 28, 2020 (Reference No.: 2020-01-017383) and April 20, 2020 (Reference No.: 2020-01-035221), which are presented herein by means of reference. |
| Pledged assets | None. There is a future commitment that during the period commencing from the date on which the Company's debentures (Series A) are fully repaid and so long as the debentures (Series B) are still outstanding, the Company will not create a general floating lien on its assets and rights, existing and future, in favor of any third party without the conditions stipulated in the trust certificate being fulfilled. |
| Is the series material | Yes. |
The Company is in compliance with all the conditions of the Company's debentures (Series A) and (Series B) and the trust certificates. The Company was not required to take any action in accordance with the request of the trustees for the said debentures.
As part of the Company's policies with respect to contributions, in the period of the Report, a contribution, in amount of NIS 170 thousand, was approved to The Society for Assistance to the Elderly and Needy Persons in the Persons in the Period of the Coronavirus.
Presented below are significant updates and/or changes with respect to the Company's business, which occurred since the signing date of the Company's Periodic Report for 2019, on February 26, 2020 and up to publication of this Report.
13.1 Section 2.3.1 (signing of agreements for acquisition of shares of Zomet and the concentration format) to Part A to the Periodic Report
Further to that stated in Section 2.3.1 to Part A to the Periodic Report regarding the Company's undertaking in a set of agreements for acquisition of shares of Zomet. For details regarding payment of the balance of the consideration in respect of the transaction for acquisition of 95% of the issued and paid-up share capital of Zomet – see Section 4 to the introduction to the Report of the Board of Directors.
For details regarding binding agreements signed with customers in the distribution network and the transmission network and operation of an energy generation facility on the customer's premises (yard) and arrangements for sale of energy to customers, further to that stated in Section 2.3.3 to Part A to the Periodic Report – see Section 10 to the introduction to the Report of the Board of Directors.
13.3 Section 2.3 (nature and results of every significant structural change, merger or acquisition; acquisition, sale or transfer of assets in a significant scope not in the ordinary course of business)
For details regarding the Company's undertaking with IDE, which received notification that it won in a tender of the State of Israel for construction, operation, maintenance and transfer of a seawater Desalinization Facility on the "Sorek B" site, in an agreement for construction, operation and maintenance of a power plant powered by natural gas on the premises of the Desalinization Facility – see Section 12 to the introduction to the Report of the Board of Directors.
13.4 Section 7.8.5 to Part A to the Periodic Report
For details regarding a bid submitted by the Company and the Noy Fund in the tender for sale of the Ramat Hovav power plant, which was published by Israel Electric Company, further to that stated in Section 7.8.5 to Part A to the Periodic Report – see the Company's Immediate Report dated May 20, 2020 (Reference No.: 2020-01-044872), and Section 11 to the Report of the Board of Directors.
15 Update of the Company's Business including in this Report of the Board of Directors was prepared in accordance with Regulation 39A of the Reporting Regulations, and includes significant changes or new items that occurred in the Company's business from the publication date of the Periodic Report for 2019 and up to the publication date of this Report. It is noted that in some of the case an additional description was provided in order to present a more comprehensive picture of the matter addressed. Reference to Immediate Reports as part of this Report includes the information included in the said Immediate Reports by means of reference.
Regarding the decision of the Electricity Authority to extend the commercial operation date stated in Hadera's conditional license further to the request submitted to the Electricity Authority and approval of the lenders in the Hadera Financing Agreement to extend the last date for commercial operation stipulated in the Hadera Financing Agreement further to Hadera's request to the lenders, as stated in in Section 8.2.4 to Part A to the Periodic Report – see Section 3 to the introduction to the Report of the Board of Directors.
For details regarding postponement of the maintenance work planned for April 2020 at Rotem Power Plant due to restrictions imposed due to spread of the Coronavirus – see the Company's Immediate Report dated March 11, 2020 (Reference No.: 2020-01-019948) and Section 5 to the introduction to the Report of the Board of Directors.
For details regarding fulfillment of the preconditions determined in the revisions to Rotem's agreements for supply of natural gas with the Tamar Group and with Energean as stated in Sections 8.13.1 and 8.13.6 to the Periodic Report – see the Company's Immediate Report dated March 11, 2020 (Reference No.: 2020-01-019945).
For details regarding fulfillment of the preconditions determined in the revision to Hadera's agreement for supply of natural gas with the Tamar Group as stated in Sections 8.13.3 to the Periodic Report – see the Company's Immediate Report dated March 26, 2020 (Reference No.: 2020-01-026854).
For details regarding a notice received by the Company from the Hadera construction contract in connection with possible impacts of spread of the Coronavirus on completion of the work in the Hadera Power Plant, as stated in Section 8.14.1.1 to Part A to the Periodic Report – see the Company's Immediate Report dated March 11, 2020 (Reference No.: 2020-01-019948).
For details regarding the impact of spread of the Coronavirus on the construction period of the Zomet Power Plant and amendment of the Zomet construction agreement, including issuance of a Work Commencement Order to Zomet's construction contractor – see Section 4 to the introduction to the Report of the Board of Directors.
13.12 Section 10 (financing) to Part A to the Periodic Report
For details regarding a loan taken out by the Company in place of short-term credit, as stated in Section 10 to Part A to the Periodic Report – see Notes 5E and 5F to the interim financial statements.
For details regarding changes in the amount of the bank guarantee and cash deposit of the Company to secure investment of shareholders' equity in Zomet – see Note 5G to the interim financial statements.
13.15 Section 10.8 (credit rating) to Part A to the Periodic Report
For details regarding granting of a rating of ilA– with a stable rating outlook from Maalot and A3.il with a stable rating outlook from Midroog for issuance of debentures in an amount of up to NIS 400 million – see the Company's Immediate Reports dated February 28, 2020 (Reference No.: 2020-01-017383 and 2020-01-017380) and the Amending Report dated April 20, 2020 (Reference No.: 2020-01-035221).
Commencing from April 27, 2020 and the start of trading of the Company's debentures (Series B). For additional details – see the Company's Immediate Report dated April 26, 2020 (Reference No.: 2020-01-036967).
For details regarding holdings of interested parties and senior officers in the Company as at March 31, 2020 – see the Company's Immediate Report dated April 5, 2020 (Reference No.: 2020-01-036117). For details regarding changes in the holdings of interested parties and senior officers subsequent to the date of the said position of the holdings – see the Company's Immediate Report dated May 4, 2020 (Reference No.: 2020-01-039586).
For details regarding changes in the position of the Company's capital and convertible securities subsequent to the date of the Periodic Report – see the Company's Immediate Report dated April 26, 2020 (Reference No.: 2020-01-036967).
Avisar Paz Giora Almogy Chairman of the Board of Directors CEO
Date: May 26, 2020
Exhibit 99.2
(Unaudited)
| Auditors' Review Report | 2 |
|---|---|
| Condensed Consolidated Interim Statements of Financial Position | 3 – 4 |
| Condensed Consolidated Interim Statements of Income | 5 |
| Condensed Consolidated Interim Statements of Comprehensive Income | 6 |
| Condensed Consolidated Interim Statements of Changes in Equity | 7 – 8 |
| Condensed Consolidated Interim Statements of Cash Flows | 9 – 10 |
| Notes to the Condensed Consolidated Interim Financial Statements | 11 – 29 |
Millennium Tower 17 Ha'arba'a St., POB 609, Tel-Aviv 6100601
03-6848000

We have reviewed the accompanying financial information of OPC Energy Ltd. (hereinafter – "the Company") and its subsidiaries, including the condensed consolidated interim statement of financial position as at March 31, 2020 and the condensed consolidated interim statements of income, comprehensive income, changes in equity and cash flows for the three-month period then ended. The Board of Directors and Management are responsible for the preparation and presentation of financial information for this interim period in accordance with IAS 34 "Financial Reporting for Interim Periods", and are also responsible for the preparation of financial information for this interim period in accordance with Section D of the Securities Regulations (Periodic and Immediate Reports), 1970. Our responsibility is to express a conclusion on the financial information for this interim period based on our review.
We conducted our review in accordance with Review Standard (Israel) 2410 "Review of Financial Information for Interim Periods Performed by the Independent Auditor of the Entity" of the Institute of Certified Public Accountants in Israel. A review of financial information for interim periods consists of making inquiries, primarily of persons responsible for financial and accounting matters, and applying analytical and other review procedures. A review is substantially less in scope than an audit conducted in accordance with generally accepted auditing standards in Israel and consequently does not enable us to obtain assurance that we would become aware of all significant matters that might be identified in an audit. Accordingly, we do not express an audit opinion.
Based on our review, nothing has come to our attention that causes us to believe that the above-mentioned financial information was not prepared, in all material respects, in accordance with International Accounting Standard IAS 34.
In addition to that mentioned in the previous paragraph, based on our review, nothing has come to our attention that causes us to believe that the above-mentioned financial information does not comply, in all material respects, with the disclosure requirements of Section D of the Securities Regulations (Periodic and Immediate Reports), 1970.
Sincerely,
Somekh Chaikin Certified Public Accountants (Isr.)
May 26, 2020
| At March 31 | At December 31 | |||
|---|---|---|---|---|
| 2020 | 2019 | 2019 (Audited) |
||
| (Unaudited) | ||||
| In Thousands of New Israeli Shekels | ||||
| Current Assets | ||||
| Cash and cash equivalents | 279,404 | 448,687 | 384,748 | |
| Short-term deposits and restricted cash | 79,307 | 185,134 | 115,765 | |
| Trade receivables and accrued income | 101,602 | 120,640 | 134,794 | |
| Other receivables and debit balances | 116,420 | 25,742 | 69,975 | |
| Short-term derivative financial instruments | 616 | 648 | 188 | |
| Total current assets | 577,349 -------------- |
780,851 -------------- |
705,470 -------------- |
|
| Non-Current Assets | ||||
| Long-term deposits and restricted cash | 325,013 | 196,682 | 266,803 | |
| Long-term advance deposits and prepaid expenses |
308,504 | 88,959 | 104,317 | |
| Deferred tax assets, net | 5,263 | 3,274 | 5,240 | |
| Long-term derivative financial instruments | 8,629 | – | 7,077 | |
| Property, plant and equipment | 2,420,618 | *2,372,485 | 2,344,920 | |
| Right-of-use assets | 56,009 | *61,154 | 56,832 | |
| Intangible assets | 4,078 | 5,231 | 4,259 | |
| Total non-current assets | 3,128,114 | 2,727,785 | 2,789,448 | |
| -------------- | -------------- | -------------- | ||
| Total assets | 3,705,463 | 3,508,636 | 3,494,918 |
* Reclassified.
| At March 31 | At December 31 | |||
|---|---|---|---|---|
| 2020 | 2019 | 2019 | ||
| (Unaudited) | (Audited) | |||
| In Thousands of New Israeli Shekels | ||||
| Current Liabilities | ||||
| Short-term loans and current maturities |
374,776 | 100,704 | 157,147 | |
| Trade payables | 120,365 | 206,449 | 123,812 | |
| Dividend payable | – | 53,600 | – | |
| Other payables and credit balances | 38,512 | 37,813 | 41,641 | |
| Short-term derivative financial instruments | 23,311 | 283 | 21,678 | |
| Current maturities of lease liabilities | 2,411 | 2,367 | 2,400 | |
| Current tax liabilities | 9,725 | – | – | |
| Total current liabilities | 569,100 -------------- |
401,216 -------------- |
346,678 -------------- |
|
| Non-Current Liabilities | ||||
| Long-term loans from banks and others | 1,726,226 | 1,805,678 | 1,740,607 | |
| Debentures | 252,309 | 282,883 | 252,309 | |
| Long-term lease liabilities | 15,680 | 17,106 | 15,960 | |
| Long-term derivative financial instruments | 29,433 | – | – | |
| Other long-term liabilities | 2,340 | 1,193 | 2,307 | |
| Employee benefits | 177 | 177 | 177 | |
| Liabilities for deferred taxes, net | 287,510 | 246,379 | 281,105 | |
| Total non-current liabilities | 2,313,675 -------------- |
2,353,416 -------------- |
2,292,465 -------------- |
|
| Total liabilities | 2,882,775 | 2,754,632 | 2,639,143 | |
| -------------- | -------------- | -------------- | ||
| Equity | ||||
| Share capital | 1,433 | 1,319 | 1,433 | |
| Premium on shares | 635,283 | 361,005 | 635,283 | |
| Capital reserves | 16,340 | 83,159 | 65,384 | |
| Retained earnings | 112,987 | 234,342 | 85,226 | |
| Total equity attributable to the Company's owners | 766,043 | 679,825 | 787,326 | |
| Non-controlling interests | 56,645 | 74,179 | 68,449 | |
| Total equity | 822,688 -------------- |
754,004 -------------- |
855,775 -------------- |
|
| Total liabilities and equity | 3,705,463 | 3,508,636 | 3,494,918 |
| Avisar Paz |
|---|
| Chairman of the Board of Directors |
Giora Almogy CEO
_______________________________ ________________________ _________________________
Tzahi Goshen CFO
Approval date of the financial statements: May 26, 2020
| For the | |||||
|---|---|---|---|---|---|
| Three Months Ended | Year Ended | ||||
| March 31 | December 31 2019 |
||||
| 2020 | 2019 | ||||
| (Unaudited) | (Audited) | ||||
| In Thousands of New Israeli Shekels | |||||
| Sales | 312,551 | 353,699 | 1,329,988 | ||
| Cost of sales (net of depreciation and amortization) | 205,129 | 223,550 | 910,347 | ||
| Depreciation and amortization | 22,836 | 26,830 | 110,997 | ||
| Gross profit | 84,586 | 103,319 | 308,644 | ||
| Administrative and general expenses | 15,053 | 16,953 | 61,743 | ||
| Other income |
70 | 1,001 | 21,409 | ||
| Operating income | 69,603 ----------- |
87,367 ----------- |
268,310 ------------- |
||
| Financing expenses | 21,334 | 20,145 | 100,028 | ||
| Financing income | 5,621 | 1,282 | 6,879 | ||
| Financing expenses, net | 15,713 ----------- |
18,863 ----------- |
93,149 ------------- |
||
| Income before taxes on income |
53,890 | 68,504 | 175,161 | ||
| Taxes on income | 15,927 | 17,595 | 50,425 | ||
| Income for the period |
37,963 | 50,909 | 124,736 | ||
| Income attributable to: |
|||||
| The Company's owners | 27,761 | 39,611 | 90,495 | ||
| Non-controlling interests | 10,202 | 11,298 | 34,241 | ||
| Income for the period |
37,963 | 50,909 | 124,736 | ||
| Income per share attributable to the Company's owners |
|||||
| Basic income per share (in NIS) |
0.19 | 0.30 | 0.66 | ||
| Diluted income per share (in NIS) | 0.19 | 0.30 | 0.65 |
| For the | ||||||
|---|---|---|---|---|---|---|
| Three Months Ended March 31 |
Year Ended December 31 2019 |
|||||
| 2020 2019 |
||||||
| (Unaudited) | (Audited) | |||||
| In Thousands of New Israeli Shekels | ||||||
| Income for the period |
37,963 --------- |
50,909 --------- |
124,736 ---------- |
|||
| Components of other comprehensive loss that after the initial recognition in the statement of comprehensive income were or will be transferred to the statement of income |
||||||
| Effective portion of change in the fair value of cash-flow hedges |
(39,654) | (1,601) | (28,989) | |||
| Net change in fair value of derivative financial instruments used for hedging cash flows recorded to the cost of the hedged item |
3,444 | (71) | 4,668 | |||
| Net change in fair value of derivative financial instruments used to hedge cash flows transferred to the statement of income |
7,701 | – | 9,778 | |||
| Tax benefit (taxes) in respect of items of other comprehensive income (loss) |
(172) | 384 | 615 | |||
| Total other comprehensive loss for the period, net of tax |
(28,681) --------- |
(1,288) --------- |
(13,928) ---------- |
|||
| Total comprehensive income for the period |
9,282 | 49,621 | 110,808 | |||
| Total comprehensive income attributable to: The Company's owners Holders of non-controlling interests Total comprehensive income for the period |
(920) 10,202 9,282 |
38,323 11,298 49,621 |
76,567 34,241 110,808 |
| Attributable to the owners of the Company | ||||||||||
|---|---|---|---|---|---|---|---|---|---|---|
| Share capital |
Premium on shares |
Capital reserve for transactions with non controlling interests and in respect of merger |
Hedging reserve |
Capital reserve for transactions with shareholders |
Capital reserve for share-based payments |
Retained earnings |
Total | Non controlling interests |
Total equity |
|
| (Unaudited) In Thousands of New Israeli Shekels |
||||||||||
| For the three-month period ended March 31, 2020 |
||||||||||
| Balance at January 1, 2020 |
1,433 | 635,283 | (3,510) | (13,477) | 77,930 | 4,441 | 85,226 | 787,326 | 68,449 | 855,775 |
| Acquisition of non controlling interests Share-based payment Dividends to holders of non-controlling |
– – |
– – |
(21,147) – |
– – |
– – |
– 784 |
– – |
(21,147) 784 |
(6) – |
(21,153) 784 |
| interests Other comprehensive |
– | – | – | – | – | – | – | – | (22,000) | (22,000) |
| loss for the period, net of tax Income for the period Balance at |
– – |
– – |
– – |
(28,681) – |
– – |
– – |
– 27,761 |
(28,681) 27,761 |
– 10,202 |
(28,681) 37,963 |
| March 31, 2020 | 1,433 | 635,283 | (24,657) | (42,158) | 77,930 | 5,225 | 112,987 | 766,043 | 56,645 | 822,688 |
| For the three-month period ended March 31, 2019 |
||||||||||
| Balance at January 1, 2019 Acquisition of non |
1,319 | 361,005 | 2,598 | 451 | 77,930 | 3,770 | 230,731 | 677,804 | 80,480 | 758,284 |
| controlling interests Share-based payment |
– – |
– – |
(1,501) – |
– – |
– – |
– 1,199 |
– – |
(1,501) 1,199 |
1 – |
(1,500) 1,199 |
| Dividends to the Company's shareholders Dividends to holders |
– | – | – | – | – | – | (36,000) | (36,000) | – | (36,000) |
| of non-controlling interests Other comprehensive loss for the period, |
– | – | – | – | – | – | – | – | (17,600) | (17,600) |
| net of tax Income for the period Balance at |
– – |
– – |
– – |
(1,288) – |
– – |
– – |
– 39,611 |
(1,288) 39,611 |
– 11,298 |
(1,288) 50,909 |
| March 31, 2019 | 1,319 | 361,005 | 1,097 | (837) | 77,930 | 4,969 | 234,342 | 679,825 | 74,179 | 754,004 |
| Attributable to the owners of the Company | ||||||||||
|---|---|---|---|---|---|---|---|---|---|---|
| Share capital |
Premium on shares |
Capital reserve for transactions with non controlling interests and in respect of merger |
Hedging reserve |
Capital reserve for transactions with shareholders |
Capital reserve for share-based payments |
Retained earnings |
Total | Non controlling interests |
Total equity |
|
| In Thousands of New Israeli Shekels | ||||||||||
| For the year ended December 31, 2019 |
||||||||||
| Balance at | ||||||||||
| January 1, 2019 Issuance of shares (less issuance |
1,319 | 361,005 | 2,598 | 451 | 77,930 | 3,770 | 230,731 | 677,804 | 80,480 | 758,284 |
| expenses) Acquisition of non-controlling |
110 | 271,485 | – | – | – | – | – | 271,595 | – | 271,595 |
| interests | – | – | (6,108) | – | – | – | – | (6,108) | 5 | (6,103) |
| Share-based payment | – | – | – | – | – | 3,468 | – | 3,468 | – | 3,468 |
| Exercise of options and RSUs Issuance of capital notes |
4 | 2,793 | – | – | – | (2,797) | – | – | – | – |
| to holders of non controlling interests Dividend to the |
– | – | – | – | – | – | – | – | 240 | 240 |
| Company's shareholders Dividends to holders of non-controlling |
– | – | – | – | – | – | (236,000) | (236,000) | – | (236,000) |
| interests Elimination of rights of holders of non-controlling |
– | – | – | – | – | – | – | – | (47,600) | (47,600) |
| interests due to sale of subsidiary (see Other comprehensive loss for the year, |
– | – | – | – | – | – | – | – | 1,083 | 1,083 |
| net of tax | – | – | – | (13,928) | – | – | – | (13,928) | – | (13,928) |
| Income for the year | – | – | – | – | – | – | 90,495 | 90,495 | 34,241 | 124,736 |
| Balance at December 31, 2019 |
1,433 | 635,283 | (3,510) | (13,477) | 77,930 | 4,441 | 85,226 | 787,326 | 68,449 | 855,775 |
| For the | |||||
|---|---|---|---|---|---|
| Three Months Ended | Year Ended December 31 2019 |
||||
| March 31 2020 |
|||||
| (Unaudited) | 2019 | (Audited) | |||
| In Thousands of New Israeli Shekels | |||||
| Cash flows from operating activities | |||||
| Income for the period | 37,963 | 50,909 | 124,736 | ||
| Adjustments: | |||||
| Depreciation and amortization | 28,895 | 35,208 | 146,647 | ||
| Financing expenses, net | 15,713 | 18,863 | 93,149 | ||
| Taxes on income | 15,927 | 17,595 | 50,425 | ||
| Gain on sale of subsidiary | – | – | (1,777) | ||
| Share-based payment transactions | 784 | 1,199 | 3,468 | ||
| Revaluation of derivative financial instruments | – | 1,080 | 1,080 | ||
| 99,282 ----------- |
124,854 ----------- |
417,728 ----------- |
|||
| Change in trade and other receivables | 5,709 | 23,490 | (3,015) | ||
| Change in trade and other payables | (22,965) | 46,334 | (18,965) | ||
| (17,256) ----------- |
69,824 ----------- |
(21,980) ----------- |
|||
| Taxes on income received (paid), net | 251 ----------- |
(4,042) ----------- |
(4,189) ----------- |
||
| Net cash provided by operating activities |
82,277 ----------- |
190,636 ----------- |
391,559 ----------- |
||
| Cash flows from investing activities | |||||
| Interest received | 378 | 1,037 | 6,563 | ||
| Short-term deposits and restricted cash, net | 36,458 | (892) | 69,695 | ||
| Withdrawals from long-term restricted cash | 6,846 | 1,514 | 2,082 | ||
| Deposits in long-term restricted cash | (64,752) | (16,236) | (91,000) | ||
| Deferred consideration from sale of subsidiary less cash sold |
341 | – | 3,158 | ||
| Long-term advance deposits and prepaid expenses |
(188,409) | – | (11,184) | ||
| Acquisition of property, plant and equipment Deferred consideration in respect of acquisition of |
(51,007) | (28,690) | (121,681) | ||
| subsidiary (for details – see Note 5J) |
(46,648) | – | – | ||
| Acquisition of intangible assets | – | (282) | (919) | ||
| Payments in respect of derivative financial instruments, net | (2,742) | (1,150) | (3,313) | ||
| Net cash used in investing activities |
(309,535) ----------- |
(44,699) ----------- |
(146,599) ----------- |
||
| For the | |||||
|---|---|---|---|---|---|
| Three Months Ended March 31 |
Year Ended December 31 |
||||
| 2020 2019 |
2019 | ||||
| (Unaudited) | (Audited) | ||||
| In Thousands of New Israeli Shekels | |||||
| Cash flows from financing activities | |||||
| Interest paid | (14,916) | (15,524) | (75,841) | ||
| Costs paid in advance in respect of taking out of loans |
(13,223) | (984) | (6,535) | ||
| Dividend paid to the Company's shareholders |
– | – | (236,000) | ||
| Dividends paid to holders of non-controlling interests |
(22,000) | – | (47,600) | ||
| Investments of holders of non-controlling interests in the | |||||
| in the capital of a subsidiary | – | – | 240 | ||
| Proceeds from issuance of debentures, net of issuance | |||||
| expenses | – | – | 271,595 | ||
| Receipt of short-term loans from banks, net | 219,400 | – | – | ||
| Receipt of long-term loans from banks and others | 25,000 | – | – | ||
| Repayment of long-term loans from banks and others | (40,460) | (9,929) | (67,682) | ||
| Repayment of debentures | – | – | (11,488) | ||
| Acquisition of non-controlling interests | (25,680) | – | (1,500) | ||
| Payment in respect of derivative financial instruments | (5,324) | – | (11,370) | ||
| Repayment of principal of lease liabilities | (331) | (583) | (1,562) | ||
| Net cash provided by (used in) financing activities |
122,466 ----------- |
(27,020) ----------- |
(187,743) ----------- |
||
| Increase (decrease) in cash and cash equivalents | (104,792) | 118,917 | 57,217 | ||
| Cash and cash equivalents at beginning of the period |
384,748 | 329,950 | 329,950 | ||
| Impact of changes in the currency exchange rate on the balances of cash and cash equivalents |
(552) | (180) | (2,419) | ||
| Cash and cash equivalents at end of the period | 279,404 | 448,687 | 384,748 |
OPC Energy Ltd. (hereinafter – "the Company") was incorporated in Israel on February 2, 2010. The Company's registered address is 121 Menachem Begin Blvd., Tel-Aviv, Israel. The Company is controlled by Kenon Holdings Ltd. (hereinafter – "the Parent Company"), a company incorporated in Singapore, the shares of which are "dual listed" for trading on both the New York Stock Exchange (NYSE) and the Tel-Aviv Stock Exchange Ltd. (hereinafter – "the Stock Exchange").
The Company is a publicly-held company, and its securities are traded on the stock exchange. The Company and its subsidiaries, the financial statements of which are consolidated with those of the Company (hereinafter – "the Group") are engaged in the area of generation of electricity and supply thereof to private customers and Israel Electric Company Ltd. (hereinafter – "IEC"), including initiation, development, construction and operation of power plants and facilities for the generation of energy. As at the date of the Report, the Group's activities are carried on only in Israel. The Group's electricity generation activities and the supply thereof focus on generation of electricity using conventional technology and cogeneration technology. The Group is also taking action to construct an open-cycle power plant using conventional technology (a Peaker plant).
The Company owns two power plants: the Rotem power plant, which is owned by OPC Rotem Ltd. (hereinafter – "Rotem") (which is held by the Company (80%) and by another shareholder (20%)), which operates using conventional technology having generation capacity of about 466 megawatts (MW); and OPC Hadera Ltd. (hereinafter – "Hadera"), which is currently in the test-run stage of the power plant and its commercial operation date is expected to be in June 2020. The Hadera Power Plant will run using cogeneration technology and having an installed capacity of up to 148.5 MW. Furthermore, Hadera owns the Energy Center, which has installed capacity of 17.9 MW, which up to the date of commercial operation of the Hadera power plant supplies all the steam consumption and part of the electricity consumption of Hadera Paper Mills Ltd. (hereinafter – "Hadera Paper"), which is located adjacent to the Hadera Power Plant (the balance of the electricity consumption of Hadera Paper is supplied by Rotem). In addition, the Company holds full ownership of Zomet Energy Ltd. (hereinafter – "Zomet"), which is taking action to construct a power plant which runs by means of natural gas using conventional technology in an open cycle (a Peaker plant) having a capacity of about 396 MW, located proximate to the Plugot Intersection, in the area of Kiryat Gat, under Regulation 914 of the Electricity Authority. In February 2020, notification was received from the Electricity Authority whereby Zomet is in compliance with the conditions for proof of a financial closing, in accordance with that stipulated in its conditional license for construction of the Zomet Power Plant and in accordance with all law. For additional details regarding Zomet – see Notes 5I through 5O.
The Group's activities are subject to regulation, including, among other things, the provisions of the Electricity Sector Law, 1996, and the regulations promulgated thereunder, resolutions of the Electricity Authority, the provisions of the Law for Promotion of Competition and Reduction of Business Concentration, 2013, the provisions of the Economic Competition Law, 1988, and the regulations promulgated thereunder, and regulation in connection with licensing of businesses, planning and construction, and environmental quality (protection). The Electricity Authority is authorized to issue licenses under the Electricity Sector Law (licenses for facilities having a generation capacity in excess of 100 MW also require approval of the Minister of Energy), supervise the license holders (including supply licenses and private generation licenses), determine tariffs and provide benchmarks for the level, nature and quality of the services that are required from a holder of a "Essential Service Provider" license. Accordingly, the Electricity Authority supervises both Israel Electric Company (IEC) and private electricity generators.
The Group's activities are subject to seasonal fluctuations as a result of changes in the official Time of Use of Electricity Tariff (hereinafter – "the TAOZ"), which is regulated and published by the Electricity Authority. The year is broken down into 3 seasons: "summer" (July and August), "winter" (December, January and February) and "transition" (March through June and September through November) and for each season a different tariff is set. The Company's results are based on the generation component, which is part of the TAOZ, and as a result there is a seasonal effect.
At the end of 2019 and in the first quarter of 2020, there was an outbreak in China and thereafter throughout the world of the Coronavirus (COVID-19), which in March 2020 was declared as a worldwide pandemic by the World Health Organization (hereinafter – "the Coronavirus Crisis"). Due to the Coronavirus Crisis, in the period of the Report and thereafter, movement (traffic) restrictions and restrictions on business activities were imposed by the State of Israel and countries throughout the world. In addition, the said Coronavirus crisis has caused, among other things, uncertainty and instability in the Israeli and global financial markets and economy. The operations of the Company's active power plants, Rotem Power Plant and the Energy Center are continuing in the "restrictions' period" as a result of their being "essential enterprises" while safeguarding the work teams and taking precautionary measures in order to prevent outbreak and spreading of the infection at the Company's sites. As at the date of the Report, the Coronavirus crisis had not had a significant impact on the Company's results and activities.
The Coronavirus Crisis and the movement restrictions, as referred to above, have impacted the Group's activities, as stated below:
– Taking into account the quarantine instructions and restrictions on entry into Israel as a result of spread of the Coronavirus (COVID-19), there are delays in arrival of equipment as well as arrival of a foreign technical team required for completion of the stage of the acceptance tests of the Hadera Power Plant. The Company expects that the commercial operation date of the power plant will be in June 2020, however in light of the restrictions described, the said commercial operation date could be delayed even beyond June 2020.
The condensed consolidated interim financial statements were prepared in accordance with International Accounting Standard 34 (hereinafter – "IAS 34"), "Financial Reporting for Interim Periods" and do not include all of the information required in complete, annual financial statements. These statements should be read together with the financial statements for the year ended December 31, 2019 (hereinafter – "the Annual Financial Statements"). In addition, these financial statements were prepared in accordance with the provisions of Section D of the Securities Regulations (Periodic and Immediate Reports) 1970.
The condensed, consolidated, interim financial statements were approved for publication by the Company's Board of Directors on May 26, 2020.
The New Israeli Shekel (NIS) is the currency that represents the principal economic environment in which the Group operates. Accordingly, the NIS is the functional currency of the Group. The NIS also serves as the presentation currency in these financial statements. Currencies other than the NIS constitute foreign currency.
In preparation of the condensed consolidated interim financial statements in accordance with IFRS, Company management is required to use judgment when making estimates, assessments and assumptions that affect implementation of the policies and the amounts of assets, liabilities, income and expenses. It is clarified that the actual results are likely to be different than these estimates.
Management's judgment, at the time of implementing the Group's accounting policies and the main assumptions used in the estimates involving uncertainty, are consistent with those used in the Annual Financial Statements, except for that stated in Note 1 regarding update of the estimate of the balance of the remaining useful life of various vehicles in light of postponement of the maintenance at Rotem, and in Note 3.
A. The Group's accounting policies in these condensed consolidated interim financial statements are the same as the policies applied in the Annual Financial Statements.
The Amendment clarifies whether a transaction to acquire activities is the acquisition of a "business" or an asset. For purposes of this examination, the Amendment added the possibility of utilizing the concentration test so that if substantially all of the fair value of the acquired assets is concentrated in a single identifiable asset or a group of similar identifiable assets, the acquisition will be of an asset. In addition, the minimum requirements for definition as a business have been clarified, such as for example the requirement that the acquired processes be substantive so that in order for it to be a business, the operation shall include at least one input element and one substantive process, which together significantly contribute to the ability to create outputs. Furthermore, the Amendment narrows the reference to the outputs element required in order to meet the definition of a business and examples were added illustrating the aforesaid examination. The Amendment is effective for transactions to acquire an asset or business for which the acquisition date is in annual periods beginning on or after January 1, 2020.
The Amendments include a number of mandatory leniencies that are relevant to examination of the effectiveness of hedge accounting ratios that are impacted by uncertainty deriving from reform of the IBOR interest rates (this reform is intended to result in cancellation of interest rates such as LIBOR and EURIBOR). For example:
The Amendments are to be applied retroactively commencing from January 1, 2020. The leniencies included as part of the Amendments will be discontinued prospectively at the earlier of: clarification of the uncertainty arising from the reform or the date on which the hedge ratios are discontinued.
In the Group's estimation, application of the Amendments did not have a significant impact on the financial statements.
The Amendment replaces certain classification requirements of liabilities as current or non-current. For example, pursuant to the Amendment, a liability will be classified as non-current where an entity has a right to postpone the payment for a period of at least 12 months after the period of the report, which is "material" and exists at the end of the period of the report. A right exists as at the date of the report only if an entity is in compliance with the conditions for postponement of the payment as at this date. In addition, the Amendment clarifies that a conversion right of a liability will impact is classification as current or non-current, unless the conversion component is capital.
The Amendment will enter into effect for reporting periods commencing on January 1, 2022. Early application is permissible. The Amendment is to be applied retroactively, including adjustment of the comparative data. The Group has not yet commenced examination of the impacts of application of the Amendment on the financial statements.
The Amendment cancels the requirement whereby in calculation of the costs that may be attributed directly to property, plant and equipment, a reduction is to be made from the costs of testing the proper functioning of the asset for the net proceeds from sale of any items produced in the process (such as samples produced at the time of testing the equipment). Instead, the said proceeds are to be recognized in the statement of income in accordance with the relevant standards and the cost of the items sold is to be measured pursuant to the measurement requirements of IAS 2 "Inventory".
The Amendment will enter into effect for reporting periods commencing on January 1, 2022 or thereafter. Early application is permissible. The Amendment is to be applied retroactively, including revision of the comparative data, but only for items of property, plant and equipment that were brought to the location and position required for them to be able to function in the manner contemplated by management after the earliest reporting period presented on the initial application date of the Amendment. The cumulative impact of the Amendment will adjust the opening balance of the retained earnings of the earliest reporting period presented.
The Group has not yet commenced examining the impacts of the Amendment on the financial statements.
The carrying amounts in the books of certain financial assets and liabilities, including short-term and long-term deposits, cash and cash equivalents, restricted cash, trade receivables, other receivables, derivative financial instruments, short-term loans and credit, trade payables and other payables are the same as or approximate their fair values.
The fair values of the other financial assets and liabilities, together with the carrying amounts shown in the statement of financial position, are as follows:
| At March 31, 2020 | ||
|---|---|---|
| Book | Fair | |
| Value* | Value | |
| In Thousands of NIS | ||
| Loans from banks and others | 1,852,542 | 2,063,530 |
| Debentures | 286,180 | 311,061 |
| 2,138,722 | 2,374,591 | |
| At March 31, 2019 | ||
| Book | Fair | |
| Value* | Value | |
| In Thousands of NIS | ||
| Loans from banks and others | 1,896,402 | 2,239,296 |
| Debentures | 297,300 | 321,587 |
| 2,193,702 | 2,560,883 | |
| At December 31, 2019 | ||
| Book | Fair | |
| Value* | Value | |
| In Thousands of NIS | ||
| Loans from banks and others | 1,867,448 | 2,243,290 |
| Debentures | 282,864 | 324,623 |
| 2,150,312 | 2,567,913 | |
* Includes current maturities and accrued interest.
Derivative financial instruments are measured at fair value, using the Level 2 valuation method. The fair value is measured using the discounted future cash flows method, on the basis of observable data.
In addition, the Company enters into transactions in derivative financial instruments in order to hedge foreign currency risks and risks of changes in the CPI. Derivative financial instruments are recorded based on their fair value. The fair value of the derivative financial instruments is based on prices, rates and interest rates that are received from banks, brokers and through customary trading software. The fair value of the derivative financial instruments is estimated on the basis of the data received, using valuation and pricing techniques that are characteristic of the various instruments in the different markets. The fair value measurement of long-term derivative financial instruments is estimated by discounting the cash flows deriving from them, based on the terms and maturity of each instrument and using market interest rates for similar instruments as at the measurement date. Changes in the economic assumptions and the valuation techniques could materially affect the fair value of the instruments.
Set forth below is data regarding the representative rates of exchange and the Consumer Price Index (CPI):
| CPI (in points) |
Exchange rate of the dollar against shekel |
Exchange rate of the euro against shekel |
|
|---|---|---|---|
| March 31, 2020 | 100.3 | 3.565 | 3.900 |
| March 31, 2019 | 100.2 | 3.632 | 4.078 |
| December 31, 2019 | 100.8 | 3.456 | 3.878 |
| Change during the three-month period ended: |
|||
| March 31, 2020 | (0.5%) | 3.1% | 0.6% |
| March 31, 2019 | (0.3%) | (3.1%) | (4.9%) |
| Change during the year ended: | |||
| December 31, 2019 | 0.3% | (7.8%) | (9.6%) |
According to the Decision, the said amendment will apply to Rotem after determination of supplemental arrangements for Rotem, which as the date of the Report had not yet been determined, and the Company is closely monitoring this matter. Therefore, as the publication date of the Report there is no certainty regarding the extent of the unfavorable impact of the Decision, if any, on the Company's activities.
C. In the first quarter of 2020, the Group acquired property, plant and equipment not for cash, in the amount of about NIS 13 million (in the first quarter of 2019 – about NIS 13 million).
N. In January 2020, ILA approved allotment of an area measuring about 85 dunams for purposes of construction of the Zomet Power Plant (hereinafter in this Section – "the Land") and it signed a development agreement with Kibbutz Netiv Halamed Heh (hereinafter – "the Kibbutz") in connection with the Land, which is valid up to November 5, 2024, which after fulfillment of its conditions a lease agreement will be signed for a period of up to November 4, 2044. In addition, in January 2020, the option agreement signed by Zomet and the Kibbutz for lease of the Land expired, and as part of its cancellation the parties signed an agreement of principles for establishment of a joint company, Zomet Netiv Limited Partnership (hereinafter – "the Joint Company" and "the Agreement of Principles for Establishment of the Joint Company", respectively). Subsequent to the date of the Report, in May 2020, transfer of the rights from the Kibbutz to Joint Company in the registration records of ILA was made.
The Joint Company was established by the Company and the Kibbutz as a limited partnership under the name "Zomet Netiv Limited Partnership", where the composition of the partners therein is: (1) General Partner – will hold 1% of the Joint Company; and the shares of the General Partner will be held by the Kibbutz (26%) and Zomet (74%); (2) limited partners – the Kibbutz and Zomet will hold 26% and 73% of the rights in the Joint Company as limited partners, respectively.
As part of the agreement of principles for establishment of the Joint Company, it was provided that the Kibbutz will sell to the Joint Company its rights in the Land by force of which it will be possible to sign a development agreement with ILA – this being in exchange for an aggregate amount of NIS 30 million, plus VAT as per law, which the Joint Company paid to the Kibbutz in the period of the Report (amounts that were provided to it by Zomet). In the Agreement of Principles for Establishment of the Joint Company it was clarified that the Kibbutz acted as a trustee of the Joint Company when it signed the Development Agreement with ILA, and acted as an agent of the Joint Company when it signed the financial specification by virtue of which capitalization fees for the Land were paid, in the amount of about NIS 207 million (as detailed below). The Kibbutz also undertook that it will act as an agent and a trustee of the Joint Company, for all intents and purposes, in connection with every report that is required in connection with the transaction that is the subject of the above-mentioned agreement of principles and regarding every matter that will be required from it by the Joint Company. Further to that stated above, in February 2020, an updated lease agreement was also signed whereby the Joint Company, as the owner of the Land, will lease the Land to Zomet, for the benefit of the project.
Zomet (Cont.)
After approval by the competent authorities of ILA for allotment of the land for purposes of construction of the Zomet Power Plant, in January 2020, a financial specification was received from ILA in respect of the capitalization fees, whereby value of the Land (not including development expenses) was set based on the assessment at the amount of about NIS 207 million (not including VAT) (hereinafter – "the Initial Assessment"). The Initial Assessment is subject to control procedures that have not yet been completed and it may be updated at the close of the said control procedures. Pursuant to that stated in the Initial Assessment and for purposes of completion of the land transaction and receipt of the building permit (which was received in January 2020 and is required in order to receive approval of the Electricity Authority for the financial close for the Zomet Project), Zomet, in the name of the Joint Company and by means of the Kibbutz, arranged payment of the Initial Assessment in January 2020 at the rate of 75% of amount of the Initial Assessment and provided through the Company, the balance, at the rate of 25% as a bank guarantee in favor of ILA. For details regarding a short-term loan the Company took out in order to pay the Initial Assessment, as stated, – see Note 5E. It is noted that the assessment in preliminary and there is no certainty regarding the amount of the final assessment that will be received. Pursuant to the arrangement with ILA, the Company will be permitted to contest the amount of the assessment when the final assessment is received after the conclusion of the required control processes. The Company intends to examine filing of a contest of the final assessment on the relevant dates. Furthermore, subsequent to the date of the Report, in April 2020, the Company provided a bank guarantee, in the amount of about NIS 12.5 million, at the request of the Taxes Authority in Israel, which requested to examine whether the Joint Company is subject to Purchase Tax in respect of payment of the capitalization fees made for the Land. In the position of Zomet, based on its legal advisors, it is more reasonable than not that the Joint Company will not be charged for payment of Purchase Tax, as stated and accordingly no provision was included in the financial statements.
In addition, further to that stated in Note 24A3 to the Annual Financial Statements, regarding imposition of development levies to the Shafir Local Council (hereinafter – "the Council"), in January 2020 the Council sent Zomet a charge notification in respect of calculation of the levies, in the amount of NIS 36.5 million, of which in December 2019 the amount of NIS 13 million, which is not in dispute, was paid. In light of that stated, the Company updated the amount of the automatic guarantee it provided for Zomet in favor of the Council in respect of the amount in dispute between the parties to about NIS 24 million. In March 2020, Zomet filed an administrative petition against the Council in respect of the amount in dispute, as stated. As at the publication date of the Report, a hearing on the matter had not yet been held. In Zomet's estimation, based on an opinion of its legal advisors, it is more reasonable than not that Zomet will not be required to pay an additional amount beyond the amount it paid in respect of the development levies and, accordingly, no provision was included in the financial statements.
Zomet (Cont.)
N. (Cont.)
All of the amounts paid in respect of the Land, as stated, were classified in the Company's statement of financial position as at March 31, 2020 as "advance deposits" in the "long-term receivables" category since transfer of the rights from the Kibbutz to the Joint Company in the records of ILA has not yet been made as at the date of the Report. In light of transfer of the rights from the Kibbutz to the Joint Company in the records of ILA subsequent to the date of the Report, in May 2020, the amounts paid in respect of the land, as stated, will be reclassified in the Company's statement of financial position as at June 30, 2020 to the category "right-of-use assets".
O. In January 2020, Zomet signed an agreement for acquisition of available capacity and energy and provision of infrastructure services between Zomet and Israel Electric Company (IEC). As part of the agreement, Zomet undertook to sell energy and available capacity from its facility to IEC, and IEC committed to provide Zomet infrastructure services and management services for the electricity system, including back-up services – all of this in accordance with that stipulated in the agreement, the provisions of law and the benchmarks. Pursuant to the terms of the agreement, part of the rights and obligations of IEC pursuant to the agreement will be assigned in the future to the System Administrator.
The agreement will remain in effect up to the end of the period in which Zomet is permitted to sell available capacity and energy in accordance with the provisions of its generation license (that is, up to the end of 20 years from the commercial operation date of Zomet). Nonetheless, in a case where IEC will be prevented from acquiring available capacity and energy due non-extension of its license or receipt of an alternative license, the agreement will come to an end on the date on which the preventing factor, as stated, occurs. The agreement provides that Zomet will allot all of the power plant's capacity to a fixed availability arrangement, where a condition for acquisition of fixed availability will be compliance with mandatory criteria, as stipulated in Regulation 914. The power plant will be operated based on the directives of the System Administrator, pursuant to the provisions of Regulation 914. Furthermore, the agreement includes provisions that cover connection of the power plant to the electricity grid, provisions relating to the planning, construction and maintenance of the power plant, and provisions addressing acquisition of the power plant's available capacity.
The agreement provides, among other things, that the System Administrator will be permitted to disconnect supply of the electricity to the electricity grid if Zomet does not comply with the safety provisions as provided by law or a safety provision of the System Administrator that were delivered to it in advance and in writing. In addition, Zomet committed to comply with the availability and credibility requirements stipulated in its license and in Regulation 914, and to pay for non-compliance therewith, in accordance with that provided in Regulation 914.
Rotem (Cont.)
V. In February 2020, the Rating Committee of Midroog Ltd. (hereinafter – "Midroog") reconfirmed Rotem's long-term rating at the level of Aa2 with a stable rating outlook and the rating of Rotem's senior debt at the level of Aa2 with a stable rating outlook.
Breakdown of the revenues from sales:
| For the | ||||
|---|---|---|---|---|
| Three Months Ended March 31 |
||||
| 2020 | 2019 | 2019 | ||
| (Unaudited) (Audited) In Thousands of New Israeli Shekels |
||||
| Revenues from sale of electricity | 296,420 | 337,858 | 1,271,200 | |
| Revenues from sale of steam | 16,131 | 15,841 | 58,788 | |
| 312,551 | 353,699 | 1,329,988 |
B. (Cont.)
The trust certificate includes customary grounds for calling the debentures for immediate repayment (subject to the cure periods provided), including insolvency events, liquidation proceedings, receivership, a stay of proceedings and creditors' arrangements, certain structural changes, a significant worsening in the Company's position, etc. In addition, there is a right to call the debentures for early repayment: (1) in a case of calling another debenture series (traded on the Stock Exchange or on the Consecutive Institutional System) issued by the Company or other financial debt (or a number of debts, as stated, cumulatively) of the Company and of subsidiaries (not including a case of calling for immediate repayment of non-recourse debt), including foreclosure of guarantees (which secure repayment of debt to a financial creditor) provided by the Company or by subsidiaries to a creditor, in an amount that is not less than U.S.\$40 million; (2) upon breach of financial covenants provided during two consecutive examination periods; (3) in a case as stated in subsection (2) (this being even without waiting for the second examination period), if the Company executed an unusual transaction with a controlling shareholder (that is not in accordance with the Companies Regulations (Leniencies in Transactions with Interested Parties), 2000, without receipt of advance approval from the holders of the debentures in a special decision); (4) if an asset or number of assets of the Company was/were sold in an amount constituting more than 50% of the value of the assets in the consolidated financial statements during a consecutive period of 12 months or upon executing a change in the Company's main activities ("the Company's main activities" – the energy sector, including the area of generation of energy from power plants and from renewable energy sources); (5) upon occurrence of certain events of loss of control by the controlling shareholder; (6) in a case of discontinuance of a rating for a certain period of time; (7) in a case of discontinuance of trading for a certain period of time or elimination of the debentures from trading; (8) if the Company ceases to be a reporting corporation; (9) in a case where a "going concern" caveat is recorded in the Company's financial statements relating only to the Company itself, for a period of two consecutive quarters; and (10) if the Company breaches its commitment not to create a general floating lien on its existing and future assets and rights in favor of any third party without the conditions provided in the trust certificate having been fulfilled – all of the above as detailed in the trust certificate signed between the Company and Reznik Paz Nevo Trusts Ltd. on April 22, 2020.
In addition, the trust certificate includes a commitment of the Company to comply with financial covenants and restrictions provided (including restrictions applicable to a distribution, restrictions applicable to expansion of a series, provisions for adjustment of interest in a case of a rating change or non-compliance with a financial covenant). Financial covenants include compliance with a ratio of the consolidated net financial debt less the financial debt designated for construction of projects that have not yet commenced producing EBITDA, to the adjusted EBITDA that does not exceed 13 (and for purposes of a distribution as defined in the trust certificate that does not exceed 11), there must be minimum shareholders' equity of NIS 250 million (and for purposes of a distribution NIS 350 million), and the ratio of the shareholders' equity to the total assets must be at a rate that is not less than 17% (and for purposes of a distribution a rate that is not less than 27%).
B. (Cont.)
As at March 31, 2020: (1) the Company's shareholders' equity was NIS 765 million; (2) the ratio of the shareholders' equity to the Company's total assets was 58%; (3) the ratio of the net consolidated financial debt less the financial debt designated for construction of projects that have not yet commenced producing EBITDA and the adjusted EBITDA is 3.45.
In addition, the trust certificate includes a commitment not to create a general floating lien on the Company's existing and future assets and rights in favor of any third party without one of the conditions provided in the draft trust certificate having been fulfilled – all of this in accordance with the conditions provided in the trust certificate (it is clarified that the Company and/or related companies (including partnerships) will be permitted to create a fixed or floating lien on a Company asset or assets, without any of the said conditions having been fulfilled).
The terms of the debentures also include the possibility of an increase in the interest rate in certain cases of a change of the rating and in certain cases of non-compliance with a financial covenant (in accordance with clauses provided in the trust certificate). The Company's ability to expand the debenture series was limited under certain conditions, including maintenance of the rating of the debentures as it was immediately preceding expansion of the series and an absence of a breach.
| Tranche No. | Vesting Conditions | Expiration Dates |
|---|---|---|
| st tranche 1 |
At the end of 12 months from the grant date | At the end of 36 months from the vesting date |
| nd tranche 2 |
At the end of 24 months from the grant date | At the end of 24 months from the vesting date |
| rd tranche 3 |
At the end of 36 months from the grant date | At the end of 24 months from the vesting date |
| th tranche 4 |
At the end of 48 months from the grant date | At the end of 24 months from the vesting date |
The exercise price of each of the options issued is NIS 25.81 (unlinked). The exercise price is subject to certain adjustments (including in respect of distribution of dividends, issuance of rights, etc.).
The average fair value of each option granted was estimate proximate to the issuance date, using the Black and Scholes model, at NIS 7.76 per option. The calculation is based on a standard deviation of 31.48%, a risk-free interest rate of 0.36% to 0.58% and an expected life of 4 to 6 years. The fair value of the RSU Units was estimated based on the price of a Company share on May 11, 2020, which was NIS 26.80.
The cost of the benefit embedded in the options based on the fair value on the date of their issuance amounted to about NIS 1,540 thousand. This amount will be recorded in the statement of income over the vesting period of each tranche.
E. In May 2020, the Company signed an agreement (through a designated company that is wholly owned by the Company ("the Subsidiary")) with SMS IDE Ltd. ("IDE"), which on May 26, 2020 received notification that it won a tender of the State of Israel for construction, operation, maintenance and transfer of a seawater desalinization facility on the "Sorek B" site ("the Desalinization Facility"), whereby if IDE signs a BOT agreement with the State of Israel, the Subsidiary will construct, operate and maintain a power plant powered by natural gas with a generation capacity of up to 99 MW on the premises of the Desalinization Facility ("the Power Plant"), and will supply the energy required for the Desalinization Facility for a period of 25 years ("the IPP Agreement"). The Power Plant is expected to be constructed under the "Regulation for Generators of Ultra-High Voltage that are Established Without a Competitive Process", which was published by the Electricity Authority in March 2019.
Building tools?
Free accounts include 100 API calls/year for testing.
Have a question? We'll get back to you promptly.